PRIOR PRINTER'S NO. 755 PRINTER'S NO. 1147
No. 656 Session of 2005
INTRODUCED BY GORDNER, PILEGGI, COSTA, WAUGH, BOSCOLA, ROBBINS, WOZNIAK, ERICKSON, C. WILLIAMS, PIPPY, PUNT, D. WHITE, M. WHITE AND LEMMOND, APRIL 29, 2005
SENATOR PILEGGI, URBAN AFFAIRS AND HOUSING, AS AMENDED, SEPTEMBER 27, 2005
AN ACT 1 Providing for dispute resolution procedures relating to <-- 2 residential construction defects between contractors and 3 homeowners or members of associations; and prescribing 4 penalties. 5 PROVIDING FOR DISPUTE RESOLUTION PROCEDURES RELATING TO <-- 6 RESIDENTIAL CONSTRUCTION DEFECTS BETWEEN CONTRACTORS AND 7 HOMEOWNERS OR MEMBERS OF ASSOCIATIONS. 8 The General Assembly of the Commonwealth of Pennsylvania 9 hereby enacts as follows: 10 Section 1. Short title. <-- 11 This act shall be known and may be cited as the Residential 12 Construction Dispute Resolution Act. 13 Section 2. Definitions. 14 The following words and phrases when used in this act shall 15 have the meanings given to them in this section unless the 16 context clearly indicates otherwise: 17 "Action." A civil lawsuit, judicial action or arbitration 18 proceeding asserting a claim, in whole or in part, for damages 19 or other relief in connection with a dwelling, caused by a
1 construction defect. 2 "Association." An association as defined under 68 Pa.C.S. §§ 3 3103 (relating to definitions), 4103 (relating to definitions) 4 and 5103 (relating to definitions). 5 "Claimant." Any person who asserts a claim concerning a 6 construction defect. 7 "Construction defect." The term shall have the same meaning 8 assigned by a written express warranty either provided by the 9 contractor or required by applicable statutory law. If no 10 written express warranty or applicable statutory warranty 11 provides a definition, then the term shall mean a matter 12 concerning the design or construction of a dwelling, or an 13 alteration of or addition to an existing dwelling or of an 14 appurtenance to a dwelling on which a person has a complaint 15 against a contractor. The term may include any physical damage 16 to the dwelling, any appurtenance or the real property on which 17 the dwelling or appurtenance is affixed, proximately caused by a 18 construction defect. 19 "Consultant." An engineer, architect, contractor, inspector 20 or other person purporting to have expertise relating to 21 residential construction. 22 "Contractor." A person, firm, partnership, corporation, 23 association or other organization that is engaged in the 24 business of developing, constructing or selling newly 25 constructed dwellings or constructing additions or appurtenances 26 to an existing dwelling. The term includes an owner, officer, 27 director, shareholder, partner or employee of a contractor. For 28 purposes of this act, the term also includes an industrialized 29 housing manufacturer. The term does not include a real estate 30 agent or broker. 20050S0656B1147 - 2 -
1 "Dwelling." A single-family house or duplex. The term 2 includes a multifamily unit designed for residential use in 3 which title to each individual unit is transferred to the owner. 4 Under a condominium or cooperative system, the term includes 5 common areas and improvements that are owned or maintained by an 6 association or by members of an association. The term includes 7 the systems, other components, improvements, other structures 8 and recreational facilities that are appurtenant to the house, 9 duplex or multifamily unit but not necessarily a part of the 10 house, duplex or multifamily unit. For purposes of this act, the 11 term also includes industrialized housing. 12 "Industrialized housing." A structure designed primarily for 13 residential occupancy and which is wholly or in substantial part 14 made, constructed, fabricated, formed or assembled in 15 manufacturing facilities for installation or assembly and 16 installation on the building site so that concealed parts or 17 processes of manufacture cannot be inspected at the site without 18 disassembly, damage or destruction. The term does not include a 19 structure or building classified as an institutional building or 20 manufactured home, as defined by the National Manufactured 21 Housing Construction and Safety Standards Act of 1974 (Public 22 Law 93-383, 42 U.S.C. § 5401-5426). 23 "Industrialized housing manufacturer." A person, firm, 24 partnership, corporation, association or other organization 25 involved in the process of making, constructing, fabricating, 26 forming or assembling, in a manufacturing facility, for 27 installation or assembly and installation on the building site, 28 industrialized housing from raw, unfinished or semifinished 29 materials. 30 "Serve" or "service." For an individual, delivery by 20050S0656B1147 - 3 -
1 certified mail, return receipt requested, to the last known 2 address of an addressee. For a corporation, limited partnership, 3 limited liability company or other registered business 4 organization, the term shall mean delivery on the registered 5 agent or other agent for service of process authorized by the 6 laws of this Commonwealth. 7 Section 3. Notice and opportunity to repair. 8 In every action subject to this act, the claimant shall, no 9 later than 60 days before initiating an action against a 10 contractor, provide service of written notice of claim on that 11 contractor. The notice of claim shall state that the claimant 12 asserts a construction defect claim or claims and is providing 13 notice of the claim or claims pursuant to the requirements of 14 this act. The notice of claim shall describe the claim or claims 15 in detail sufficient to explain the nature of the alleged 16 construction defects and the results of the defects. Service of 17 the notice of the claim shall be the equivalent of service of a 18 lawsuit or demand for arbitration with respect to imposing on 19 the contractor a legal obligation to pay as damages the cost of 20 any repairs and/or monetary payment made to settle the claim. In 21 addition, the claimant shall provide to the contractor any 22 evidence that depicts the nature and cause of the construction 23 defect, including expert reports, photographs and videotapes, if 24 that evidence would be discoverable under this Commonwealth's 25 evidentiary rules. If, after proper request, the claimant fails 26 to provide such evidence, then the claimant shall not be 27 permitted to introduce any such evidence not produced into 28 evidence in any action. 29 Section 4. Personal injury or death claims. 30 This act shall not apply to any claim for personal injury or 20050S0656B1147 - 4 -
1 death. 2 Section 5. Procedure. 3 (a) Contents of notice.-- 4 (1) In an action subject to this act, the claimant must, 5 at least 60 days before initiating the action against a 6 contractor, provide service of written notice of claim on 7 that contractor. The notice of claim shall: 8 (i) State that the claimant asserts a construction 9 defect claim and is providing notice of the claim 10 pursuant to requirements of this act. 11 (ii) Describe the claim in detail sufficient to 12 explain the nature of the construction defect and the 13 result of the defect. 14 (iii) Include any reports by consultants that 15 describe the construction defect that the claimant 16 possesses. 17 (2) Service under this subsection shall toll all 18 applicable statutes of limitations until 60 days after the 19 receipt of the notice of claim. 20 (b) Response.--Except as otherwise provided for under 21 subsection (g), within 15 days after service of the notice of 22 claim under subsection (a), the contractor that has received the 23 notice of claim may serve on the claimant and on any other 24 contractor that has received the notice of claim a written 25 response to the claim, which either: 26 (1) offers to settle the claim by monetary payment, the 27 making of repairs or a combination of both, without 28 inspection, including a timetable for the making of the 29 payment or repairs; 30 (2) proposes to inspect the dwelling that is the subject 20050S0656B1147 - 5 -
1 of the claim within 15 days; or 2 (3) rejects the claim. 3 (c) Inspection of dwelling.-- 4 (1) If the contractor requests the opportunity to 5 inspect the dwelling under subsection (b)(2), the claimant 6 shall provide the contractor and its consultants complete 7 access to inspect the dwelling in order to document the 8 defect and perform any destructive or nondestructive tests 9 necessary to evaluate the claim. If testing is performed, the 10 contractor shall return the dwelling to its pretesting 11 condition. 12 (2) If an inspection reveals a condition that requires 13 additional testing, the contractor shall provide notice to 14 the claimant of the need for the additional testing and the 15 claimant shall provide access to the dwelling. 16 (3) If a claim is asserted on behalf of owners of 17 multiple dwellings or multiple owners of units within a 18 multifamily complex, the contractor shall be entitled to 19 inspect each of the dwellings or units. 20 (d) Process following inspection.--Within 15 days following 21 completion of an inspection or testing under subsection (c), the 22 contractor may serve a written response on the claimant which: 23 (1) offers to settle the claim by monetary payment, the 24 making of repairs or a combination of both, and includes a 25 timetable for making the payment or repairs; or 26 (2) rejects the claim. 27 (e) Notice of claimant's response.-- 28 (1) The claimant shall accept or reject an offer by a 29 contractor under subsection (b)(1) or (2) and (d)(1) within 30 15 days of receipt of the offer. 20050S0656B1147 - 6 -
1 (2) If the claimant rejects the settlement offer made by 2 the contractor under subsection (b) or (d), the claimant 3 shall provide written notice of the claimant's rejection to 4 the contractor and include the specific reasons for the 5 claimant's rejection. 6 (3) If the claimant fails to respond as required under 7 paragraph (1), the contractor's offer of monetary payment or 8 offer to repair shall be deemed to be accepted. 9 (f) Claimant's ability to bring action.--If the contractor: 10 (1) rejects the claim; 11 (2) does not respond to a notice of claim made under 12 subsection (a); or 13 (3) does not make monetary payment or repair within the 14 proposed timetable, 15 the claimant may bring an action against the contractor for the 16 defect described in the notice of claim without further notice 17 and notwithstanding the 60-day time period set forth under 18 subsection (a). 19 (g) Construction defects involving physical safety of 20 occupants.-- 21 (1) If a construction defect poses an imminent threat to 22 the physical safety of the occupants of the dwelling, the 23 notice shall so advise the contractor, and the deadline for 24 the contractor's initial response under subsection (b) shall 25 be seven days after receipt of the notice. 26 (2) If the contractor's response under subsection (b) 27 contains a request to inspect the dwelling, the contractor 28 shall arrange for the inspection within five days. 29 (3) If the contractor determines there is an imminent 30 threat to physical safety, the contractor shall provide the 20050S0656B1147 - 7 -
1 claimant with a proposal for a monetary offer or offer to 2 repair within three days of the determination. If the 3 contractor determines there is no imminent threat to public 4 safety, the contractor shall respond as provided in 5 subsection (d). 6 (4) During the course of any notice to an inspection by 7 the contractor, the claimant or contractor may take such 8 interim repair steps to maintain the structural integrity of 9 the dwelling without prejudicing its claims or defenses. 10 (h) Right of action.-- 11 (1) If a claimant rejects a reasonable monetary offer or 12 reasonable supplemental monetary offer or does not permit the 13 contractor to repair the defect pursuant to an accepted offer 14 to repair under subsection (e), the claimant may not recover 15 an amount in excess of: 16 (i) the fair market value of an offer to repair the 17 construction defect or the actual cost of the repairs, 18 whichever is less; or 19 (ii) the amount of the monetary offer of settlement. 20 (2) For purposes of this subsection, the trier of fact 21 shall determine the reasonableness of a monetary offer or 22 offer to repair made under subsection (b). If the claimant 23 has rejected a reasonable monetary offer or offer to repair, 24 the claimant may not recover costs or attorney fees incurred 25 after the date of rejection. 26 (i) Timely access for repairs.--If a claimant accepts a 27 contractor's offer to repair a construction defect, the claimant 28 shall provide the contractor and its subcontractors, agents, 29 experts and consultants access to the dwelling to complete the 30 repairs within the timetable set forth under this section. 20050S0656B1147 - 8 -
1 (j) Agreement between claimant and contractor.--Following 2 service under subsection (a), a claimant and a contractor may 3 alter the procedures under this act by mutual written agreement. 4 (k) Limitation of liability.--In an action involving a 5 construction defect, a contractor shall not be liable for 6 damages caused by: 7 (1) Normal shrinkage due to drying or settlement of 8 construction components within the tolerance of building 9 standards. 10 (2) The contractor's reasonable reliance on written 11 information relating to the dwelling that was obtained from 12 official government records or provided by a government 13 entity. 14 (3) Refusal of the claimant to allow the contractor or 15 the contractor's agents to perform their warranty service 16 work. 17 Section 6. Additional construction defects. 18 A construction defect that is discovered after a claimant has 19 served notice under section 5(a) (relating to procedure) may not 20 be alleged in an action until the claimant has complied with the 21 requirements of section 5. 22 Section 7. Actions of homeowner associations. 23 (a) General prohibition.--No person may provide or offer to 24 provide anything of value, directly or indirectly, to a property 25 manager of an association or to a member or officer of an 26 association to induce the property manager, member or officer to 27 encourage or discourage the association to file a claim for 28 damages arising from a construction defect. 29 (b) Property managers.--No property manager retained by an 30 association or member or officer of an association may accept 20050S0656B1147 - 9 -
1 anything of value, directly or indirectly, in exchange for 2 encouraging or discouraging the association to file a claim for 3 damages arising from a construction defect. 4 (c) Penalty.--A person who knowingly violates subsection (a) 5 or (b) commits a misdemeanor of the third degree. 6 Section 8. Right of action for association. 7 An association may bring an action against a contractor to 8 recover damages resulting from construction defects in any of 9 the common elements or limited common elements of a common- 10 interest community. The action may be maintained only after: 11 (1) A majority of the board of directors of the 12 association and the contractor have met in person and 13 conferred in a good faith attempt to resolve the 14 association's claim or the contractor has definitively 15 declined or ignored the requests to meet with the board of 16 directors of the association. Prior notice of a meeting under 17 this paragraph shall be provided to all board members and to 18 the contractor. 19 (2) The association has complied with section 5 20 (relating to procedure). 21 Section 9. Destructive tests. 22 No association may employ a person to perform destructive 23 tests to determine any damage or injury to a unit, common 24 element or limited common element caused by a construction 25 defect unless: 26 (1) The person performing the test has provided a 27 written schedule for repairs. 28 (2) The person performing the test is required to repair 29 all damage resulting from the tests in accordance with 30 Commonwealth laws and local ordinances relating thereto. 20050S0656B1147 - 10 -
1 (3) The association or the person so employed obtains 2 all permits required to conduct the tests and to repair any 3 damage resulting from the tests. 4 (4) Reasonable prior notice and opportunity to observe 5 the tests is given to the contractor against whom an action 6 may be brought as a result of the tests. 7 Section 10. Contractor employed by association. 8 The board of directors of an association may, without giving 9 notice to the unit owners, employ a contractor and such other 10 persons as are necessary to make such immediate repairs to a 11 unit or common element within the association as are required to 12 protect the health, safety and welfare of the units' owners. 13 Section 11. Construction. 14 Nothing in this act shall be construed as establishing a 15 cause of action on behalf of any claimant or contractor. 16 Section 12. Notice required at time of contracting. 17 (a) Written notice.--Upon entering into a contract to 18 construct a dwelling or to complete a remodeling project on a 19 dwelling, the contractor shall give the potential claimant a 20 written notice worded substantially as follows: 21 NOTICE CONCERNING CONSTRUCTION DEFECTS 22 Pennsylvania law contains important requirements you must 23 follow before you may file a lawsuit for defective 24 construction against the contractor who constructed your 25 dwelling or completed your remodeling project. 26 Pennsylvania law requires you to deliver to the 27 contractor a written notice by certified mail of any 28 construction conditions that you believe are defective 29 before you file your lawsuit, and you must provide your 30 contractor the opportunity to make an offer to repair or 20050S0656B1147 - 11 -
1 pay for the alleged defects. You are not obligated to 2 accept any offer made by the contractor, but failure to 3 accept a reasonable offer can limit your recoverable 4 damages. There are strict deadlines and procedures under 5 Pennsylvania law and failure to follow them may affect 6 your ability to file a lawsuit. 7 (b) Type of notice.--The notice required under subsection 8 (a) shall be in ten-point boldface type or greater and shall be 9 included within the contract between the contractor and 10 potential claimant. 11 Section 13. Applicability. 12 This act shall apply as follows: 13 (1) This act shall not apply to a contractor's right to 14 seek contribution, indemnity or recovery against a 15 subcontractor, supplier or design professional for any claim 16 made against the contractor by a claimant. 17 (2) This act shall apply regardless of the date of sale 18 or substantial completion of a dwelling, consistent with 42 19 Pa.C.S. § 5536. 20 Section 14. Effective date. 21 This act shall take effect in 60 days. 22 SECTION 1. SHORT TITLE. <-- 23 THIS ACT SHALL BE KNOWN AND MAY BE CITED AS THE RESIDENTIAL 24 CONSTRUCTION DISPUTE RESOLUTION ACT. 25 SECTION 2. DEFINITIONS. 26 THE FOLLOWING WORDS AND PHRASES WHEN USED IN THIS ACT SHALL 27 HAVE THE MEANINGS GIVEN TO THEM IN THIS SECTION UNLESS THE 28 CONTEXT CLEARLY INDICATES OTHERWISE: 29 "ACTION." A CIVIL LAWSUIT, JUDICIAL ACTION OR ARBITRATION 30 PROCEEDING ASSERTING A CLAIM, IN WHOLE OR IN PART, FOR DAMAGES 20050S0656B1147 - 12 -
1 OR OTHER RELIEF IN CONNECTION WITH A DWELLING CAUSED BY A 2 CONSTRUCTION DEFECT. 3 "ASSOCIATION." AN ASSOCIATION AS DEFINED UNDER 68 PA.C.S. §§ 4 3103 (RELATING TO DEFINITIONS), 4103 (RELATING TO DEFINITIONS) 5 AND 5103 (RELATING TO DEFINITIONS). 6 "CLAIMANT." ANY PERSON WHO ASSERTS A CLAIM CONCERNING A 7 CONSTRUCTION DEFECT. THE TERM INCLUDES AN ASSOCIATION. 8 "CONSTRUCTION DEFECT." THE TERM SHALL HAVE THE SAME MEANING 9 ASSIGNED BY A WRITTEN EXPRESS WARRANTY EITHER PROVIDED BY THE 10 CONTRACTOR OR REQUIRED BY APPLICABLE STATUTORY LAW. IF NO 11 WRITTEN EXPRESS WARRANTY OR APPLICABLE STATUTORY WARRANTY 12 PROVIDES A DEFINITION, THE TERM SHALL MEAN A MATTER CONCERNING 13 THE DESIGN OR CONSTRUCTION OF A DWELLING OR ADDITION TO A 14 DWELLING OR AN APPURTENANCE TO A DWELLING ON WHICH A PERSON HAS 15 A COMPLAINT AGAINST A CONTRACTOR. THE TERM MAY INCLUDE ANY 16 PHYSICAL DAMAGE TO THE DWELLING OR ANY APPURTENANCE, OR THE REAL 17 PROPERTY ON WHICH THE DWELLING OR APPURTENANCE IS AFFIXED, 18 PROXIMATELY CAUSED BY A CONSTRUCTION DEFECT. 19 "CONSULTANT." AN ENGINEER, ARCHITECT, CONTRACTOR, INSPECTOR 20 OR OTHER PERSON PURPORTING TO HAVE EXPERTISE RELATING TO 21 RESIDENTIAL CONSTRUCTION OR HAVING THAT EXPERTISE AS A RESULT OF 22 TRAINING OR PROFESSION. 23 "CONTRACTOR." A PERSON, FIRM, PARTNERSHIP, CORPORATION, 24 ASSOCIATION OR OTHER ORGANIZATION THAT IS ENGAGED IN THE 25 BUSINESS OF DEVELOPING, CONSTRUCTING OR SELLING NEWLY 26 CONSTRUCTED DWELLINGS OR CONSTRUCTING ADDITIONS OR APPURTENANCES 27 TO AN EXISTING DWELLING. THE TERM INCLUDES AN OWNER, OFFICER, 28 DIRECTOR, SHAREHOLDER, PARTNER OR EMPLOYEE OF A CONTRACTOR. FOR 29 PURPOSES OF THIS ACT, THE TERM ALSO INCLUDES AN INDUSTRIALIZED 30 HOUSING MANUFACTURER. THE TERM DOES NOT INCLUDE A REAL ESTATE 20050S0656B1147 - 13 -
1 AGENT, BROKER OR A CONTRACTOR THAT INSTALLS A NEW DEVICE OR 2 APPURTENANCE WHICH COSTS LESS THAN $2,000. 3 "DWELLING." A SINGLE-FAMILY HOUSE OR DUPLEX. THE TERM 4 INCLUDES A MULTIFAMILY UNIT DESIGNED FOR RESIDENTIAL USE IN 5 WHICH TITLE TO EACH INDIVIDUAL UNIT IS TRANSFERRED TO THE OWNER. 6 UNDER A CONDOMINIUM OR COOPERATIVE SYSTEM, THE TERM INCLUDES 7 COMMON AREAS AND IMPROVEMENTS THAT ARE OWNED OR MAINTAINED BY AN 8 ASSOCIATION OR BY MEMBERS OF AN ASSOCIATION. THE TERM ALSO 9 INCLUDES THE SYSTEMS, OTHER COMPONENTS, IMPROVEMENTS, OTHER 10 STRUCTURES AND RECREATIONAL FACILITIES THAT ARE APPURTENANT TO 11 THE HOUSE, DUPLEX OR MULTIFAMILY UNIT BUT NOT NECESSARILY A PART 12 OF THE HOUSE, DUPLEX OR MULTIFAMILY UNIT. FOR PURPOSES OF THIS 13 ACT, THE TERM ALSO INCLUDES INDUSTRIALIZED HOUSING. 14 "INDUSTRIALIZED HOUSING." A STRUCTURE DESIGNED PRIMARILY FOR 15 RESIDENTIAL OCCUPANCY, AND WHICH IS WHOLLY OR IN SUBSTANTIAL 16 PART MADE, CONSTRUCTED, FABRICATED, FORMED OR ASSEMBLED IN 17 MANUFACTURING FACILITIES FOR INSTALLATION OR ASSEMBLY AND 18 INSTALLATION ON THE BUILDING SITE SO THAT CONCEALED PARTS OR 19 PROCESSES OF MANUFACTURE CANNOT BE INSPECTED AT THE SITE WITHOUT 20 DISASSEMBLY, DAMAGE OR DESTRUCTION. THE TERM DOES NOT INCLUDE A 21 STRUCTURE OR BUILDING CLASSIFIED AS AN INSTITUTIONAL BUILDING OR 22 MANUFACTURED HOME, AS DEFINED BY THE NATIONAL MANUFACTURED 23 HOUSING CONSTRUCTION AND SAFETY STANDARDS ACT OF 1974 (42 U.S.C. 24 §§ 5401-5426). 25 "INDUSTRIALIZED HOUSING MANUFACTURER." A PERSON, FIRM, 26 PARTNERSHIP, CORPORATION, ASSOCIATION OR OTHER ORGANIZATION 27 INVOLVED IN THE PROCESS OF MAKING, CONSTRUCTING, FABRICATING, 28 FORMING OR ASSEMBLING, IN A MANUFACTURING FACILITY, FOR 29 INSTALLATION OR ASSEMBLY AND INSTALLATION ON THE BUILDING SITE, 30 INDUSTRIALIZED HOUSING FROM RAW, UNFINISHED OR SEMIFINISHED 20050S0656B1147 - 14 -
1 MATERIALS. 2 "SERVE" OR "SERVICE." FOR AN INDIVIDUAL, DELIVERY BY 3 CERTIFIED MAIL, RETURN RECEIPT REQUESTED, TO THE LAST KNOWN 4 ADDRESS OF AN ADDRESSEE. FOR A CORPORATION, LIMITED PARTNERSHIP, 5 LIMITED LIABILITY COMPANY OR OTHER REGISTERED BUSINESS 6 ORGANIZATION, THE TERM SHALL MEAN DELIVERY TO THE REGISTERED 7 AGENT OR OTHER AGENT FOR SERVICE OF PROCESS AUTHORIZED BY THE 8 LAWS OF THIS COMMONWEALTH. 9 SECTION 3. NOTICE AND OPPORTUNITY TO REPAIR. 10 (A) NOTICE.--IN EVERY ACTION SUBJECT TO THIS ACT, THE 11 CLAIMANT SHALL, NO LATER THAN 75 DAYS BEFORE INITIATING AN 12 ACTION AGAINST A CONTRACTOR, PROVIDE SERVICE OF WRITTEN NOTICE 13 OF CLAIM ON THE CONTRACTOR. THE NOTICE OF CLAIM SHALL STATE THAT 14 THE CLAIMANT ASSERTS A CONSTRUCTION DEFECT CLAIM OR CLAIMS AND 15 IS PROVIDING NOTICE OF THE CLAIM OR CLAIMS PURSUANT TO THE 16 REQUIREMENTS OF THIS ACT. THE NOTICE OF CLAIM SHALL DESCRIBE THE 17 CLAIM OR CLAIMS SUFFICIENTLY TO EXPLAIN THE NATURE OF THE 18 ALLEGED CONSTRUCTION DEFECTS AND THE RESULTS OF THE DEFECTS. 19 (B) SERVICE.--SERVICE OF THE NOTICE OF THE CLAIM SHALL BE 20 THE EQUIVALENT OF SERVICE OF A LAWSUIT OR DEMAND FOR ARBITRATION 21 WITH RESPECT TO IMPOSING ON THE CONTRACTOR A LEGAL OBLIGATION TO 22 PAY AS DAMAGES THE COST OF ANY REPAIRS AND/OR MONETARY PAYMENT 23 MADE TO SETTLE THE CLAIM. 24 (C) EVIDENCE.--IN ADDITION, THE CLAIMANT SHALL PROVIDE TO 25 THE CONTRACTOR ANY EVIDENCE KNOWN TO THE CLAIMANT OR IN THE 26 CLAIMANT'S POSSESSION THAT DEPICTS THE NATURE AND CAUSE OF THE 27 CONSTRUCTION DEFECT, INCLUDING EXPERT REPORTS, PHOTOGRAPHS AND 28 VIDEOTAPES, IF THE EVIDENCE WOULD BE DISCOVERABLE UNDER THE 29 STATE'S EVIDENTIARY RULES. IF, AFTER PROPER REQUEST, THE 30 CLAIMANT FAILS TO PROVIDE SUCH EVIDENCE, THE CLAIMANT SHALL NOT 20050S0656B1147 - 15 -
1 BE PERMITTED TO INTRODUCE ANY EVIDENCE NOT PRODUCED AS EVIDENCE 2 IN ANY ACTION. 3 SECTION 4. PERSONAL INJURY OR DEATH CLAIMS. 4 THIS ACT SHALL NOT APPLY TO ANY CLAIM FOR PERSONAL INJURY OR 5 DEATH. 6 SECTION 5. PROCEDURE. 7 (A) CONTENTS OF NOTICE.-- 8 (1) IN AN ACTION UNDER THIS ACT, THE CLAIMANT SHALL, AT 9 LEAST 75 DAYS BEFORE INITIATING THE ACTION AGAINST A 10 CONTRACTOR, PROVIDE SERVICE OF WRITTEN NOTICE OF CLAIM ON THE 11 CONTRACTOR. THE NOTICE OF CLAIM SHALL: 12 (I) STATE THAT THE CLAIMANT ASSERTS A CONSTRUCTION 13 DEFECT CLAIM AND IS PROVIDING NOTICE OF THE CLAIM 14 PURSUANT TO THE REQUIREMENTS OF THIS ACT. 15 (II) DESCRIBE THE CLAIM SUFFICIENTLY TO EXPLAIN THE 16 NATURE OF THE CONSTRUCTION DEFECT AND THE RESULT OF THE 17 DEFECT. 18 (III) INCLUDE ANY EVIDENCE THAT DESCRIBES THE 19 CONSTRUCTION DEFECT THAT THE CLAIMANT POSSESSES. 20 (2) SERVICE UNDER THIS SUBSECTION SHALL TOLL ALL 21 APPLICABLE STATUTES OF LIMITATION UNTIL 75 DAYS AFTER RECEIPT 22 OF NOTICE OF THE CLAIM. 23 (B) RESPONSE.--EXCEPT AS OTHERWISE PROVIDED FOR UNDER 24 SUBSECTION (G), WITHIN 15 DAYS AFTER SERVICE OF THE NOTICE OF 25 CLAIM, THE CONTRACTOR THAT HAS RECEIVED THE NOTICE OF CLAIM 26 SHALL SERVE ON THE CLAIMANT AND ON ANY OTHER CONTRACTOR THAT HAS 27 RECEIVED THE NOTICE OF CLAIM A WRITTEN RESPONSE TO THE CLAIM 28 WHICH: 29 (1) OFFERS TO SETTLE THE CLAIM BY MONETARY PAYMENT, THE 30 MAKING OF REPAIRS OR A COMBINATION OF BOTH, WITHOUT 20050S0656B1147 - 16 -
1 INSPECTION, INCLUDING A TIMETABLE FOR THE MAKING OF THE 2 PAYMENT OR REPAIRS; 3 (2) PROPOSES TO INSPECT AT THE CONTRACTOR'S EXPENSE THE 4 DWELLING THAT IS THE SUBJECT OF THE CLAIM WITHIN 15 DAYS; OR 5 (3) REJECTS THE CLAIM. 6 (C) INSPECTION OF DWELLING.-- 7 (1) IF THE CONTRACTOR REQUESTS THE OPPORTUNITY TO 8 INSPECT THE DWELLING UNDER SUBSECTION (B)(2), THE CLAIMANT 9 SHALL PROVIDE THE CONTRACTOR AND ITS CONSULTANTS REASONABLE 10 AND TIMELY ACCESS TO INSPECT THE DWELLING IN ORDER TO 11 DOCUMENT THE DEFECT AND PERFORM ANY DESTRUCTIVE OR 12 NONDESTRUCTIVE TESTS NECESSARY TO EVALUATE THE CLAIM. IF 13 TESTING IS PERFORMED, THE CONTRACTOR SHALL RETURN THE 14 DWELLING TO ITS PRETESTING CONDITION. 15 (2) IF AN INSPECTION REVEALS A CONDITION THAT REQUIRES 16 ADDITIONAL TESTING, THE CONTRACTOR SHALL PROVIDE PROMPT 17 NOTICE TO THE CLAIMANT OF THE NEED FOR THE ADDITIONAL 18 TESTING, AND THE CLAIMANT SHALL PROVIDE REASONABLE AND TIMELY 19 ACCESS TO THE DWELLING. ADDITIONAL TESTING, IF NECESSARY, 20 SHALL BE COMPLETED WITHIN 15 DAYS OF THE NOTICE. 21 (3) IF A CLAIM IS ASSERTED ON BEHALF OF OWNERS OF 22 MULTIPLE DWELLINGS OR MULTIPLE OWNERS OF UNITS WITHIN A 23 MULTIFAMILY COMPLEX, THE CONTRACTOR SHALL BE ENTITLED TO 24 INSPECT EACH OF THE DWELLINGS OR UNITS FOR WHICH A DEFECT HAS 25 BEEN CLAIMED. 26 (D) PROCESS FOLLOWING INSPECTION.--WITHIN 15 DAYS FOLLOWING 27 COMPLETION OF AN INSPECTION OR TESTING UNDER SUBSECTION (C), THE 28 CONTRACTOR SHALL SERVE A WRITTEN RESPONSE ON THE CLAIMANT WHICH: 29 (1) OFFERS TO SETTLE THE CLAIM BY MONETARY PAYMENT, THE 30 MAKING OF REPAIRS OR A COMBINATION OF BOTH, INCLUDING A 20050S0656B1147 - 17 -
1 TIMETABLE FOR MAKING THE PAYMENT AND/OR REPAIRS; OR 2 (2) REJECTS THE CLAIM. 3 (E) NOTICE OF CLAIMANT'S RESPONSE.-- 4 (1) THE CLAIMANT SHALL ACCEPT OR REJECT AN OFFER BY A 5 CONTRACTOR UNDER SUBSECTION (B)(1) OR (D)(1) WITHIN 30 DAYS 6 OF RECEIPT OF THE OFFER. 7 (2) IF THE CLAIMANT REJECTS THE SETTLEMENT OFFER MADE BY 8 THE CONTRACTOR UNDER SUBSECTION (B) OR (D), THE CLAIMANT 9 SHALL PROVIDE WRITTEN NOTICE OF THE CLAIMANT'S REJECTION TO 10 THE CONTRACTOR AND INCLUDE THE SPECIFIC REASONS FOR THE 11 CLAIMANT'S REJECTION 12 (3) IF THE CLAIMANT FAILS TO RESPOND AS REQUIRED UNDER 13 PARAGRAPH (1), THE CONTRACTOR'S OFFER OF MONETARY PAYMENT OR 14 OFFER TO REPAIR SHALL BE DEEMED TO BE REJECTED. 15 (F) CLAIMANT'S ABILITY TO BRING AN ACTION.--IF THE 16 CONTRACTOR: 17 (1) REJECTS THE CLAIM; 18 (2) DOES NOT RESPOND TO A NOTICE OF CLAIM WITHIN THE 19 TIME FRAMES UNDER THIS SECTION; OR 20 (3) DOES NOT MAKE MONETARY PAYMENT OR REPAIR WITHIN THE 21 PROPOSED TIMETABLE OF AN ACCEPTED OFFER, THE CLAIMANT MAY 22 BRING AN ACTION AGAINST THE CONTRACTOR FOR THE DEFECT 23 DESCRIBED IN THE NOTICE OF CLAIM WITHOUT FURTHER NOTICE, 24 NOTWITHSTANDING THE 75-DAY TIME PERIOD SET FORTH UNDER 25 SUBSECTION (A). 26 (G) CONSTRUCTION DEFECTS INVOLVING PHYSICAL SAFETY OF 27 OCCUPANTS.-- 28 (1) IF A CONSTRUCTION DEFECT POSES AN IMMINENT THREAT TO 29 THE PHYSICAL SAFETY OF THE OCCUPANTS OF THE DWELLING, THE 30 NOTICE SHALL SO ADVISE THE CONTRACTOR, AND THE DEADLINE FOR 20050S0656B1147 - 18 -
1 THE CONTRACTOR'S INITIAL RESPONSE UNDER SUBSECTION (B) SHALL 2 BE SEVEN DAYS AFTER RECEIPT OF THE NOTICE. 3 (2) IF THE CONTRACTOR'S RESPONSE UNDER SUBSECTION (B) 4 CONTAINS A REQUEST TO INSPECT THE DWELLING, THE CONTRACTOR 5 SHALL ARRANGE FOR THE INSPECTION WITHIN FIVE DAYS. 6 (3) IF THE CONTRACTOR DETERMINES THERE IS AN IMMINENT 7 THREAT TO PHYSICAL SAFETY, THE CONTRACTOR SHALL PROVIDE THE 8 CLAIMANT WITH A PROPOSAL FOR A MONETARY OFFER OR OFFER TO 9 REPAIR WITHIN THREE DAYS OF THE DETERMINATION. 10 (4) PRIOR TO THE SUBMISSION OF AN OFFER BY THE 11 CONTRACTOR UNDER THIS SUBSECTION, EITHER THE CLAIMANT OR 12 CONTRACTOR MAY TAKE INTERIM REPAIR STEPS TO MAINTAIN THE 13 STRUCTURAL INTEGRITY OF THE DWELLING WITHOUT PREJUDICING THE 14 CLAIMANT'S OR CONTRACTOR'S CLAIMS OR DEFENSES. 15 (H) RIGHT OF ACTION.--IF A CLAIMANT REJECTS A REASONABLE 16 MONETARY OFFER OR REASONABLE SUPPLEMENTAL MONETARY OFFER OR DOES 17 NOT PERMIT THE CONTRACTOR TO REPAIR THE DEFECT PURSUANT TO AN 18 ACCEPTED OFFER TO REPAIR UNDER SUBSECTION (E), THE CLAIMANT MAY 19 NOT RECOVER AN AMOUNT IN EXCESS OF: 20 (1) THE FAIR MARKET VALUE OF THE OFFER TO REPAIR THE 21 CONSTRUCTION DEFECT OR THE ACTUAL COST OF THE REPAIRS, 22 WHICHEVER IS LESS; OR 23 (2) THE AMOUNT OF THE MONETARY OFFER OF SETTLEMENT. 24 (I) REASONABLENESS OF MONETARY OFFER OR OFFER TO REPAIR.-- 25 (1) FOR PURPOSES OF THIS SECTION, THE TRIER OF FACT 26 SHALL DETERMINE THE REASONABLENESS OF A MONETARY OFFER OR 27 OFFER TO REPAIR. IF THE CLAIMANT HAS REJECTED A REASONABLE 28 MONETARY OFFER OR OFFER TO REPAIR, THE CLAIMANT MAY NOT 29 RECOVER COSTS OR ATTORNEY FEES INCURRED AFTER THE DATE OF 30 REJECTION. 20050S0656B1147 - 19 -
1 (2) IF THE CONTRACTOR, THROUGH NO FAULT OF THE CLAIMANT, 2 FAILS TO MAKE A REASONABLE OFFER, THIS ACT SHALL NOT LIMIT 3 THE REMEDIES AVAILABLE TO A CLAIMANT. 4 (J) TIMELY ACCESS FOR REPAIRS.--IF A CLAIMANT ACCEPTS A 5 CONTRACTOR'S OFFER TO REPAIR A CONSTRUCTION DEFECT, THE CLAIMANT 6 SHALL PROVIDE THE CONTRACTOR AND ITS SUBCONTRACTORS, AGENTS, 7 EXPERTS AND CONSULTANTS REASONABLE AND TIMELY ACCESS TO THE 8 DWELLING TO COMPLETE THE REPAIRS WITHIN THE TIMETABLE SET FORTH 9 UNDER THIS SECTION. 10 (K) AGREEMENT BETWEEN CLAIMANT AND CONTRACTOR.--FOLLOWING 11 SERVICE UNDER SUBSECTION (A), A CLAIMANT AND A CONTRACTOR MAY 12 ALTER THE PROCEDURES UNDER THIS ACT, INCLUDING THE TOLLING OF 13 THE STATUTE OF LIMITATIONS, BY MUTUAL WRITTEN AGREEMENT. 14 (L) LIMITATION OF LIABILITY.--IN AN ACTION INVOLVING A 15 CONSTRUCTION DEFECT, A CONTRACTOR SHALL NOT BE LIABLE FOR 16 DAMAGES CAUSED BY: 17 (1) NORMAL SHRINKAGE DUE TO DRYING OR SETTLEMENT OF 18 CONSTRUCTION COMPONENTS WITH THE TOLERANCE OF BUILDING 19 STANDARDS. 20 (2) THE CONTRACTOR'S REASONABLE RELIANCE ON WRITTEN 21 INFORMATION RELATING TO THE DWELLING THAT WAS OBTAINED FROM 22 OFFICIAL GOVERNMENT RECORDS OR PROVIDED BY A GOVERNMENT 23 ENTITY. 24 (3) REFUSAL OF THE CLAIMANT TO ALLOW THE CONTRACTOR OR 25 THE CONTRACTOR'S AGENTS TO PERFORM THEIR WARRANTY SERVICE 26 WORK. 27 SECTION 6. ADDITIONAL CONSTRUCTION DEFECTS. 28 A CONSTRUCTION DEFECT THAT IS DISCOVERED AFTER A CLAIMANT HAS 29 SERVED NOTICE UNDER SECTION 3(A) (RELATING TO NOTICE AND 30 OPPORTUNITY TO REPAIR) MAY BE ALLEGED IN AN ACTION PROVIDED THE 20050S0656B1147 - 20 -
1 CLAIMANT COMPLIES WITH THE REQUIREMENTS OF SECTION 5 (RELATING 2 TO PROCEDURE) WITH RESPECT TO THE DEFECT. 3 SECTION 7. RIGHT OF ACTION FOR ASSOCIATION. 4 (A) GENERAL RULE.--AN ASSOCIATION MAY BRING AN ACTION 5 AGAINST A CONTRACTOR TO RECOVER DAMAGES RESULTING FROM 6 CONSTRUCTION DEFECTS IN ANY OF THE COMMON ELEMENTS OR LIMITED 7 COMMON ELEMENTS OF A COMMON INTEREST COMMUNITY. 8 (B) RESTRICTIONS.--THE ACTION MAY BE MAINTAINED ONLY AFTER: 9 (1) A MAJORITY OF THE BOARD OF DIRECTORS OF THE 10 ASSOCIATION AND THE CONTRACTOR HAVE MET IN PERSON AND 11 CONFERRED IN A GOOD FAITH ATTEMPT TO RESOLVE THE 12 ASSOCIATION'S CLAIM, OR THE CONTRACTOR HAS DEFINITIVELY 13 DECLINED OR IGNORED THE REQUESTS TO MEET WITH THE BOARD OF 14 DIRECTORS OF THE ASSOCIATION. NOTICE OF A MEETING UNDER THIS 15 PARAGRAPH SHALL BE PROVIDED TO ALL BOARD MEMBERS AND TO THE 16 CONTRACTOR. 17 (2) THE ASSOCIATION HAS COMPLIED WITH SECTION 5 18 (RELATING TO PROCEDURE). 19 SECTION 8. DESTRUCTIVE TESTS. 20 NO ASSOCIATION MAY EMPLOY A PERSON TO PERFORM DESTRUCTIVE 21 TESTS TO DETERMINE ANY DAMAGE OR INJURY TO A UNIT, COMMON 22 ELEMENT OR LIMITED COMMON ELEMENT CAUSED BY A CONSTRUCTION 23 DEFECT UNLESS REASONABLE PRIOR NOTICE AND OPPORTUNITY TO OBSERVE 24 THE TESTS ARE GIVEN TO THE CONTRACTOR AGAINST WHOM AN ACTION MAY 25 BE BROUGHT AS A RESULT OF THE TEST. 26 SECTION 9. CONTRACTOR EMPLOYED BY ASSOCIATION. 27 THE BOARD OF DIRECTORS OF AN ASSOCIATION MAY, WITHOUT GIVING 28 NOTICE TO THE UNIT OWNERS, EMPLOY A CONTRACTOR AND SUCH OTHER 29 PERSONS AS ARE NECESSARY TO MAKE SUCH IMMEDIATE REPAIRS TO A 30 UNIT OR COMMON ELEMENT WITHIN THE ASSOCIATION AS ARE REQUIRED TO 20050S0656B1147 - 21 -
1 PROTECT THE HEALTH, SAFETY AND WELFARE OF THE UNITS' OWNERS. 2 SECTION 10. CONSTRUCTION. 3 NOTHING IN THIS ACT SHALL BE CONSTRUED AS ESTABLISHING A 4 CAUSE OF ACTION ON BEHALF OF ANY CLAIMANT OR CONTRACTOR. 5 SECTION 11. NOTICE REQUIRED AT TIME OF CONTRACTING. 6 (A) FORM OF NOTICE.--UPON ENTERING INTO A CONTRACT TO 7 CONSTRUCT A DWELLING, THE CONTRACTOR SHALL GIVE THE OWNER OR 8 BUYER A WRITTEN NOTICE WORDED SUBSTANTIALLY AS FOLLOWS: 9 NOTICE CONCERNING CONSTRUCTION DEFECTS 10 PENNSYLVANIA LAW CONTAINS IMPORTANT REQUIREMENTS YOU MUST 11 FOLLOW BEFORE YOU MAY FILE ANY ACTION FOR DEFECTIVE 12 CONSTRUCTION AGAINST THE CONTRACTOR WHO CONSTRUCTED YOUR 13 DWELLING. PENNSYLVANIA LAW REQUIRES YOU TO DELIVER TO THE 14 CONTRACTOR A WRITTEN NOTICE BY CERTIFIED MAIL OF ANY 15 CONSTRUCTION CONDITIONS THAT YOU BELIEVE ARE DEFECTIVE, 16 WITH AN OPPORTUNITY TO REPAIR, BEFORE YOU FILE ANY 17 ACTION, AND YOU MUST PROVIDE YOUR CONTRACTOR: 18 (1) THE OPPORTUNITY TO MAKE AN OFFER TO REPAIR OR 19 PAY FOR THE ALLEGED DEFECTS. 20 (2) WITH ANY EVIDENCE IN YOUR POSSESSION THAT 21 DESCRIBED THE DEFECT. IF YOU DO NOT DISCLOSE SUCH 22 EVIDENCE YOU WILL NOT BE ALLOWED TO USE THE EVIDENCE IN 23 ANY ACTION. 24 YOU ARE NOT OBLIGATED TO ACCEPT ANY OFFER MADE BY THE 25 CONTRACTOR, BUT FAILURE TO ACCEPT A REASONABLE OFFER, AS 26 DETERMINED BY A COURT OR OTHER TRIER OF FACT, MAY LIMIT 27 YOUR RECOVERABLE DAMAGES. THERE ARE STRICT DEADLINES AND 28 PROCEDURES UNDER STATE LAW, AND FAILURE TO FOLLOW THEM 29 MAY AFFECT OR IMPAIR YOUR ABILITY TO FILE AN ACTION OR TO 30 SEEK RECOVERY FOR ANY DEFECTS. THERE MAY ALSO BE 20050S0656B1147 - 22 -
1 REQUIREMENTS WHICH MUST BE FOLLOWED IN A WRITTEN 2 WARRANTY. IT IS RECOMMENDED THAT YOU CONSULT WITH AN 3 ATTORNEY OF YOUR CHOOSING BEFORE ENTERING INTO ANY 4 AGREEMENT. 5 (B) ADDITIONAL REQUIREMENTS.--THE NOTICE REQUIRED UNDER 6 SUBSECTION (A) SHALL BE IN 10-POINT BOLD TYPE OR GREATER AND 7 SHALL BE INCLUDED WITHIN THE CONTRACT BETWEEN THE CONTRACTOR AND 8 POTENTIAL CLAIMANT. 9 (C) FAILURE TO INCLUDE NOTICE.--FAILURE TO INCLUDE THE 10 NOTICE SHALL DEPRIVE THE CONTRACTOR OF THE BENEFITS OF THIS ACT. 11 SECTION 12. APPLICABILITY. 12 THIS ACT SHALL APPLY AS FOLLOWS: 13 (1) THIS ACT SHALL NOT AFFECT A CONTRACTOR'S RIGHT TO 14 SEEK CONTRIBUTION, INDEMNITY OR RECOVERY AGAINST A 15 SUBCONTRACTOR, SUPPLIER OR DESIGN PROFESSIONAL FOR ANY CLAIM 16 MADE AGAINST THE CONTRACTOR BY A CLAIMANT. 17 (2) THIS ACT SHALL APPLY REGARDLESS OF THE DATE OF SALE 18 OR SUBSTANTIAL COMPLETION OF A DWELLING, CONSISTENT WITH 42 19 PA.C.S. § 5536 (RELATING TO CONSTRUCTION PROJECTS). 20 (3) THIS ACT SHALL NOT RESTRICT, MODIFY OR ALTER OR 21 OTHERWISE INTERFERE WITH THE OBLIGATIONS, TERMS OR CONDITIONS 22 OF AN INSURANCE POLICY. 23 (4) THIS ACT SHALL NOT APPLY TO AN INSURER ASSERTING A 24 CLAIM AGAINST A CONTRACTOR FOR PAYMENTS MADE BY THE INSURER 25 PURSUANT TO AN INSURANCE POLICY COVERING THE DWELLING. A 26 CLAIM UNDER THIS PARAGRAPH SHALL NOT BE PREJUDICED, REDUCED 27 OR OTHERWISE MODIFIED BECAUSE OF THE FAILURE OF THE CLAIMANT 28 TO COMPLY WITH THIS ACT. 29 SECTION 13. EFFECTIVE DATE. 30 THIS ACT SHALL TAKE EFFECT IN 60 DAYS. D11L12JS/20050S0656B1147 - 23 -